top of page

Terms & Conditions

​

Effective Date:May 2026

These Terms and Conditions (“Terms”) govern your use of the Coherent Creations website and services. By accessing our website or engaging our services, you agree to be bound by these Terms.

 

1. Services

Coherent Creations provides commercial and residential fitout, renovation, and related services.

All services are subject to:

  • Project scope

  • Written quotation

  • Business name (if applicable)

  • Agreed timelines and specifications

 

2. Quotes and Pricing

  • All quotes are based on the information provided at the time

  • Quotes may be subject to change if project scope, materials, or site conditions vary

  • Quotes are valid for a limited period (as specified in the quotation)
     

3. Variations

Any changes to the agreed scope of work must be approved in writing and may result in:

  • Additional costs

  • Adjustments to project timeline

 

4. Payments

  • Payment terms will be outlined in your quote or agreement

  • We may require deposits, progress payments, or milestone payments

  • Late payments may result in delays to work or additional charges

​

5. Invoices

Invoices will be issued in accordance with agreed milestones or project stages and must be paid within the specified timeframe.

​

6. Project Delays

We are not liable for delays caused by factors outside our control, including but not limited to:

  • Material shortages

  • Contractor availability

  • Weather conditions

  • Client-requested changes

​

7. Client Responsibilities

You agree to:

  • Provide accurate and complete project information

  • Ensure site access is available as required

  • Obtain any necessary approvals unless otherwise agreed

​

8. Warranties and Workmanship

We aim to deliver high-quality workmanship in line with industry standards. Any applicable warranties will be outlined in your project agreement.

​

9. Limitation of Liability

To the extent permitted by law, Coherent Creations is not liable for:

  • Indirect or consequential loss

  • Loss of profit or business interruption

​​

​Our liability is limited to the value of the services provided.

​​

10. Website Use

You agree not to:

  • Use this website for unlawful purposes

  • Attempt to gain unauthorised access to systems

  • Copy or reproduce content without permission​

​

11. Intellectual Property

All content on this website, including text, images, and branding, remains the property of Coherent Creations unless otherwise stated.​

​

12. Privacy

Your use of this website is also governed by our Privacy Policy.

​​

13. Changes to Terms

We may update these Terms from time to time. Updated versions will be published on this page.

​​

14. Governing Law

These Terms are governed by the laws of Australia. Any disputes will be subject to the jurisdiction of the courts in your operating state.

​

15. Contact

For any questions regarding these Terms, please contact:

​

Coherent Creations

Email: sales@coherentcreations.net

Contact Number: 0413 930 365

bottom of page